ADVERTISEMENT FOR BIDS Lafourche Parish School District Golden Meadow Middle ? Buildings 4, 5, & 10 LEGAL NOTICE ADVERTISEMENT FOR BIDS Sealed bids will be received by the Lafourche Parish School District until 2:00 PM on Thursday, November 14, 2024, at its office located at 701 East Seventh Street, Thibodaux, Louisiana, at which time bids will be publicly opened and read-aloud for the _Golden Meadow Middle ? Buildings 4, 5, & 10, 630 South Bayou Drive, Golden Meadow, LA 70357. Per RS37:2163, bids shall be submitted in an envelope displaying the Contractor's license number, except bids submitted electronically which the contractor may submit an authentic digital signature on the electronic bid proposal accompanied by the contractor's license number. It is highly recommended that the envelope be sealed and displays legibly on the exterior, the following: Addressed to the OwnerName of the ProjectContractor's name and addressSealed Bid Enclosed Official bid documents can be downloaded from Central Bidding at www.centralbidding.com. Electronic bids and/or reverse auction bids can be submitted at www.centralbidding.com. For any questions relating to the electronic bidding process, please call Central Bidding at 225-810-4814. No project Contract Documents will be provided by the Architect or Owner. Bid prices shall specifically EXCLUDE any and all taxes whatsoever. Act 1029 of 1991 exempts' local governments from state and local tax effective September 1, 1991. Bid prices shall include any shipping charges, if applicable. Each bid shall be accompanied by a bid security of NOT less than five (5%) percent of the total bid amount. Said amount shall be in the form of a Bid Bond, Certified Check, or Cashier's check drawn on a bank insured by the Federal Deposit Insurance Corporation payable to the Lafourche Parish School Board. The successful bidder shall be required to furnish the owner with a performance bond for 100% of the contract amount prior to the issuance of a contract to perform the work. No bid may be withdrawn for a period of 45 days after receipt of bids. The time of completion of this project is prime importance. All of the work required shall be completed within one hundred and eighty (180) Calendar Days from the Notice to Proceed. Should the Contractor neglect, refuse to complete the work or obtain approval from the State Fire Marshal's Office for occupancy on the date above, the Owner shall have the right to deduct from and retain out of such moneys which may be due or which may become due and payable to the Contractor, as scheduled in the Instructions To Bidders, for each and every day that such completion of the work is delayed beyond the prescribed dates, as liquidated damages and not as a penalty. If the amount due and to become due from the Owner to the Contractor is insufficient to pay in full any such liquidated damages, the Contractor shall pay the Owner the amount necessary to the effect such payment in full. Provided, however, that the Owner shall promptly notify the Contractor in writing of the manner the amount retained, deducted, or claimed as liquidated damages was computed. Bids must be submitted on the Louisiana Uniform Public Works Bid Form furnished with the Bidding Documents. Bid sheets will be issued only to contractors and/or subcontractors licensed in accordance with the provisions of R.S. 37:2150 through 2173 of the Louisiana Legislature. Contractors desiring to bid shall submit their Louisiana Contractor's License Number as evidence that they hold a license for BUILDING CONSTRUCTION that is in full force and effect. A NON-MANDATORY Pre-bid Conference will be held at 10:00 AM on Tuesday, November 5, 2024; at the project site (Golden Meadow Middle School - address above) Lafourche Parish School Board Valerie Bourgeois, President Jarod Martin, Superintendent ADVERTISING DATES: FIRST ADVERTISEMENT: 10/15/2024 SECOND DATE: 10/22/2024 THIRD DATE: 10/29/2024 Publication Dates LLOU0174879

NOTICE OF INTRODUCTION AND NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN, in accordance with the provisions of the Home Rule Charter of the Parish of Lafourche, Louisiana, that the following entitled ordinance(s) were introduced at a meeting of the Lafourche Parish Council held on Tuesday, October 8, 2024: ORDINANCE to install ANo 18 Wheelers@ signs at the entrance of Hwy 3235 turning onto West 163rd Street on each side (northside and southside) of West 163rd Street, Galliano, Louisiana, Ward (10), District (9), Parish of Lafourche, State of Louisiana; requiring the placement of ANo 18 Wheelers@ signs; and providing penalties for the violations thereof. ORDINANCE establishing AUnmuffled Compression Brakes Prohibited@ signs on Hwy 308 in Larose with one sign being placed on the southbound shoulder of Hwy 308 approximately 48= north of the intersection of Hwy 308 and LeVillage Dr.; one sign being placed on the northbound shoulder of Hwy 308 approximately 494= south of the intersection of Hwy 308 and Edward Road; one sign being placed on the southbound shoulder of Hwy 308 approximately 364= north of the intersection of Hwy 308 and East 7th Street; one sign being placed on the northbound shoulder of Hwy 308 approximately 468= east of the intersection of Hwy 308 and East Main Street; and authorizing the Parish President to sign, execute and administer said application and any and all relevant documents. ORDINANCE declaring property as surplus belonging to Lafourche Parish Government, authorizing the disposal of surplus property, authorizing the advertising of surplus items for sale, authorizing the acceptance of the highest qualified bidders, and any remaining items that are deemed to have no value will be properly discarded; and authorizing the Parish President to sign, execute and administer any and all relevant documents. ORDINANCE granting a variance from the Lafourche Parish Subdivision regulations from the 70 feet width lot frontage reducing to 60 feet width lot frontage to Cane Ridge Phase 3 as recommended by the Lafourche Parish Planning Commission at their September 25, 2024 meeting. NOTICE IS HEREBY FURTHER GIVEN, in accordance with Article V, Section 2, of said Home Rule Charter, that the Parish Council will hold a general public hearing on the aforesaid proposed ordinance(s), at a meeting of the Parish Council, to be held at FIVE O=CLOCK (5:00) P.M., on TUESDAY, OCTOBER 22, 2024, in the Mathews Government Complex, 4876 Highway 1, Mathews, Louisiana; at which public hearing any resident of the Parish shall have a right to speak on the proposed ordinances. After holding the public hearing, the Parish Council may consider enactment of the proposed ordinances, or may defer such action to a later date. The proposed ordinances are on file at the offices of the Lafourche Parish Council, 402 Green Street, Thibodaux, Louisiana, and are available for public inspection during regular business hours, Monday through Thursday. LAFOURCHE PARISH COUNCIL, By:/s/ Carleen B. Babin, Council Clerk PUBLISH ON: OCTOBER 15, 2024 #10663873

Legal Notice-Advertisement for Bids Sealed bids will be received by the Lafourche Parish School Board until 2:00 PM on November 8, 2024, at its office located at 701 East Seventh Street, Thibodaux, Louisiana, at which time bids will be publicly opened andread-aloud for the LPSB Hurricane Ida ? Roof Repairs, Renovations, and Demolition at Golden Meadow Lower Elementary School and South Lafourche High School. Per RS37:2163, bids shall be submitted in an envelope displaying the Contractor's license number, except bids submitted electronically which the contractor may submit an authentic digital signature on the electronic bid proposal accompanied by the contractor's license number. It is highly recommended that the envelope be sealed and displays legibly on the exterior, the following: 1. Addressed to the Owner 2. Name of the Project 3. Contractor's name and address 4. Sealed Bid Enclosed Official bid documents can be downloaded from Central Bidding at www.centralbidding.com. Electronic bids and/or reverse auction bids can be submitted at www.centralbidding.com. For any questions relating to the electronic bidding process, please call Central Bidding at 225-810-4814. No project Contract Documents will be provided by the Architect or Owner. Bid prices shall specifically EXCLUDE any and all taxes whatsoever. Act 1029 of 1991 exempts' local governments from state and local tax effective September 1, 1991. Bid prices shall include any shipping charges, if applicable. Each bid shall be accompanied by a bid security of NOT less than five (5%) percent of the total bid amount. Said amount shall be in the form of a Bid Bond, Certified Check, or Cashier's check drawn on a bank insured by the Federal Deposit Insurance Corporation payable to the Lafourche Parish School Board. The successful bidder shall be required to furnish the owner with a performance bond for 100% of the contract amount prior to the issuance of a contract to perform the work. No bid may be withdrawn for a period of 45 days after receipt of bids. The time of completion of this project is prime importance. All of the work required shall be completed within One Hundred Eighty (180) Calendar Days from the Notice to Proceed. Should the Contractor neglect, refuse to complete the work or obtain approval from the State Fire Marshal's Office for occupancy on the date above, the Owner shall have the right to deduct from and retain out of such moneys which may be due or which may become due and payable to the Contractor, as scheduled in the Instruction To Bidders, for each and every day that such completion of the work is delayed beyond the prescribed dates, as liquidated damages and not as a penalty. If the amount due and to become due from the Owner to the Contractor is insufficient to pay in full any such liquidated damages, the Contractor shall pay the Owner the amount necessary to the effect such payment in full. Provided, however that the Owner shall promptly notify the Contractor in writing of the manner the amount retained, deducted, or claimed as liquidated damages was computed. Bids must be submitted on the Louisiana Uniform Public Works Bid Form furnished with the Bidding Documents. Bid sheets will be issued only to contractors and/or subcontractors licensed in accordance with the provisions of R.S. 37:2150 through 2173 of the Louisiana Legislature. Contractors desiring to bid shall submit their Louisiana Contractor's License Number as evidence that they hold a license for Building construction that is in full force and effect. A NON-MANDATORY Pre-bid Conference will be held on Tuesday, October 22, 2024 at 10:00 AM beginning at Golden Meadow Lower Elementary School located at 118 Alcide Street, Golden Meadow, Louisiana, 70357 then moving to South Lafourche High School located at 16911 East Main Street, Cut Off, Louisiana 70345. Lafourche Parish School Board Ms. Valerie Bourgeois, President Jarod Martin, Superintendent ADVERTISING DATES: FIRST ADVERTISEMENT: October 11, 2024 SECOND DATE: October 15, 2024 THIRD DATE: October 21, 2024 Publication Dates LLOU0173482

ADVERTISEMENT FOR BIDS The Board of Waterworks Commissioners Lafourche Parish Water District No. 1 Post Office Box 399 Lockport, LA 70374 DISTRIBUTION SURPLUS ITEMS- COLD WATER METERS 2024-2 Separate sealed bids will be received by the Lafourche Parish Water District No. 1 at the Administration Office 1219 Crescent Ave, Lockport, LA 70374 until 2:30 o'clock p.m., Tuesday, November 12, 2024, at which time and place said proposals will be publicly opened and read aloud for the sale of Distribution Surplus Items- Cold Water Meters- 2024-2. Above items to be sold in its existing condition. Any proposal received after the announced closing time will be returned unopened. All proposals shall be sealed and plainly marked "DISTRIBUTION SURPLUS ITEMS- COLD WATER METERS 2024-2 Surplus items may be viewed at the South Water Treatment Plant 5753 Hwy 308 Lockport, LA 70374 on weekdays between the hours of 8:00 a.m. and 4:00 p.m. by appointment only. Bid proposal form may be obtained by calling Lafourche Parish Water District No. 1 (985-532-6924) or from http://www.centralbidding.com. Electronic bidding must be submitted through http://www.centralbidding.com prior to the electronic bidding deadline. LAFOURCHE PARISH WATER DISTRICT NO. 1 /s/ Wayne Gautreaux, General Manager 10/15, 10/23, 10/31/24 #10655272

ADVERTISEMENT FOR BIDS Sealed bids will be received by the Board of Waterworks Commissioners of Lafourche Parish Water District No. 1 (herein called the District), at the General Managers office, Administrative Building, 5753 Hwy 308, Lockport, LA 70374 until 2:00 P.M., on November 12, 2024. ANY PERSON REQUIRING SPECIAL ACCOMMODATIONS SHALL NOTIFY THE DISTRICT OF THE TYPE(S) OF ACCOMMODATION REQUIRED NOT LESS THAN SEVEN (7) DAYS BEFORE THE BID OPENING. FOR: North Barrios Street Waterline Replacement The project includes the following work: Installation of approximately 3,100 linear feet of 8 C-900 waterline, along with fire hydrants, fittings, services, etc. Bidders wanting to visit the site may do so at their discretion. Complete Bid Documents for this project are available in electronic form. They may be obtained without charge and without deposit from https://www.central auctionhouse.com. Printed copies are not available from the Owner, but arrangements can be made to obtain them through most reprographic firms. Plan holders are responsible for their own reproduction costs. Questions about this procedure shall be directed to the Owner at: PHONE (985)532-6924 The Contract Documents, consisting of Advertisement for Bids, Information for Bidders, Bid, Bid Bond, Agreement, General Conditions, Supplementary Conditions, General Requirements, Payment Bond, Performance Bond, Notice of Award, Notice to Proceed, Change Order, Drawings, Specifications and Addenda may be examined at the following location: Office of Technical Assistant Administrative Building Lafourche Parish Water District No. 1 Lockport, Louisiana 70374 All bids shall be accompanied by bid security in an amount of five percent (5.0%) of the sum of the base bid and all alternates. The form of this security shall be as stated in the Instructions to Bidders included in the Bid Documents for this project. The successful Bidder shall be required to furnish a Performance and Payment Bond written as described in the Instructions to Bidders included in the Bid Documents for this project. Bids shall be accepted from Contractors who are licensed under LA. R.S. 37:2150-2192 for the classification of Municipal and Public Works Construction. Bidder is required to comply with provisions and requirements of LA R.S. 38:2212(B)(5). No bid may be withdrawn for a period of forty-five (45) days after receipt of bids, except under the provisions of LA. R.S. 38:2214. The Owner reserves the right to reject any and all bids for just cause. In accordance with La. R.S. 38:2212(B)(1), the provisions and requirements of this Section; and those stated in the bidding documents shall not be waived by any entity. BOARD OF WATERWORKS COMMISSIONERS LAFOURCHE PARISH WATER DISTRICT NO. 1 /s/ Sidney Triche Sidney Triche, President October 15th, 2024 10/15, 10/23, 10/31/24 #10655248

Notice of Sale On October 23rd, 2024, at 10:00 am or after, in accordance with LA RS: 4759, WEST PARK SELF STORAGE, 6767 West Park Ave. Houma, LA 70364 units will sell at for unpaid rent to the HIGHEST BIDDER for CASH ONLY. Cassandra M. Charles CC-06, Dresser. TV. Totes, Etc. Dionne T. Harris Twiggs CB-17, Toys, Highchair, Boxes Etc., Lionel Singleton Jr. A-030, Bed Frame, Chairs, Boxes, Etc., Melanie C. Holly, Melanie Holly Morgan E-20, Luggage, Shelves, Boxes, Etc., Lionel Singleton Jr. D-06, Disp. Cab, Ladder, Totes, Etc. Esturado Alarado, Esturado J Alarado CE-36, Totes, Chairs, Boxes, Etc., Shantel Parfait G06, Washer/Dryer, Rugs, Boxes, Etc., Crystal M Blanchard L-22, Chair, Table, Boxes, Etc., Troy A Boudreaux Jr. E-21, High Chair, Shelf, Totes ,Etc., Arch A Bell B-33, Yard Tools, Tent, Bags, Etc., Barbara Dupre, Barbara A. Dupre K-24, Tool box, Stove, Boxes, Etc., Gulf Solutions, LLC C/O Christopher Dufour RV-081, Motorboat Tag-La1121FC., Torris M Cunningham RV-100, Box Container: Tools, Wood, Etc., Torris M Cunningham RV-101, Tools, Shelves, Boxes, Etc., SOLD AS IS FOR PARTS ONLY. Publication Dates LLOU0175085

Houma-Terrebonne Regional Planning Commission Robbie Liner Chairman Jan Rogers Vice-Chairman Barry Soudelier Secretary/Treasurer Michael Billiot Member Terry Gold Member Clarence McGuire Member Angele Poiencot Member Travion Smith Member Wayne Thibodeaux Member OCTOBER 17, 2024, THURSDAY 6:00 P.M. TERREBONNE PARISH COUNCIL MEETING ROOM Government Tower, 8026 Main Street, 2nd Floor, Houma, Louisiana AGENDA I. CONVENE AS THE ZONING & LAND USE COMMISSION A. INVOCATION & PLEDGE OF ALLEGIANCE B. ROLL CALL C. CONFLICTS DISCLOSURE D. APPROVAL OF MINUTES 1. Approval of Minutes of Zoning & Land Use Commission for the Regular Meeting of September 19, 2024 E. COMMUNICATIONS F. NEW BUSINESS: 1. Home Occupation: Establish a massage therapy business; 405 South Street; Sandra Johnson, applicant G. STAFF REPORT H. COMMISSION COMMENTS: 1. Zoning & Land Use Commissioners Comments 2. Chairman Comments I. PUBLIC COMMENTS J. ADJOURN II. CONVENE AS THE REGIONAL PLANNING COMMISSION A. INVOCATION & PLEDGE OF ALLEGIENCE B. ROLL CALL C. CONFLICTS DISCLOSURE D. APPROVAL OF MINUTES: 1. Houma-Terrebonne Regional Planning Commission Minutes for the Regular Meeting of September 19, 2024 E. APPROVE REMITTANCE OF PAYMENT FOR THE OCTOBER 17, 2024 INVOICES AND THE TREASURERS REPORT OF SEPTEMBER 2024 1. Martin & Pellegrin, CPAs to present 2023 Annual Audit for ratification and acceptance F. COMMUNICATIONS G. APPLICATIONS / NEW BUSINESS: 1. a) Subdivision: Tracts 1 & 2, A Redivision of Property belonging to Louis J. Eschete, Jr. Approval Requested: Process D, Minor Subdivision Location: 3557 & 3559 Bayou Black Drive, Terrebonne Parish, LA Government Districts: Council District 7 / Bayou Black Fire District Developer: Louis Eschete, Jr. Surveyor: Keneth L. Rembert Land Surveyors b) Public Hearing c) Consider Approval of Said Application H. STAFF REPORT I. ADMINISTRATIVE APPROVAL(S): 1. Revised Tracts 1 & 2, A Redivision of Property belonging to Nicholas T. LeBlanc, et al; Section 21, T17S-R16E, Terrebonne Parish, LA (4266 & 4270 Southdown Mandalay Road / Councilman Danny Babin, District 7) 2. Redivision of Tract A, Gulf South Square into Tracts A-1 & A-2 on Property belonging to DeFraites Associates, Inc.; Section 105, T17S-R17E, Terrebonne Parish, LA (991 Grand Caillou Road / Councilwoman Kim Chauvin, District 8) J. COMMITTEE REPORT: 1. Subdivision Regulations Review Committee K. COMMISSION COMMENTS: 1. Planning Commissioners Comments 2. Chairmans Comments L. PUBLIC COMMENTS M. ADJOURN 10658149 10/11 10/14 10/15/24

INVITATION TO BIDDERS Sealed bids will be received on October 30, 2024, by the Terrebonne Council on Aging, Inc., at the office of Milford & Associates, Inc., 1538 Polk Street, in Houma, LA until 2:00 P.M., at which time and place publicly open the bids and read aloud. Bid documents will be posted on http://www.cenralauctionhouse.com To view these, download, and receive bid notices by e-mail, you will have to register with Central Auction House. Vendors/Contractors will have the option to submit their bids electronically or by paper copy. For information about the electronic submittal process, contact Ted Fleming with Central Auction House at 1-866-570-9620. Each bid shall be either hand delivered by the bidder or his agent, or such bid shall be submitted electronically with Central Auction House. No bid received after the scheduled time for opening will be considered. Failure to hand deliver the bids timely shall not be considered due cause for the scheduled time of the bid opening to be extended. Project Name: A proposed Building Renovation for: Eastside Senior Center Terrebonne Council on Aging 114 Rome Commercial Place, Houma, LA Bids must be submitted on the Louisiana Uniform Public Works Bid Form furnished with the Bidding Documents. This Project shall require a Louisiana Contractors License number for "BUILDING CONSTRUCTION". Bidding Documents for this project are on file in the office of the engineer, Milford & Associates, Inc., 1538 Polk Street, Houma, LA and can be obtained in a PDF format electronically at no cost by sending your request to milfordassociate@bellsouth.net. Plan holders are responsible for their own reproduction cost. Please contact F.E. Milford, III, P.E. at 985-868-2561 or by email at milfordassociate@bellsouth.net for any clarification or information regarding the bidding documents. A mandatory Pre-Bid Conference will be held on October 16, 2024 at 2 p.m. at the project site location, 114 Rome Commercial Place, Houma, LA 70363. The Terrebonne Council on Aging, Inc., reserves the right to reject any and all bids in accordance with Louisiana State Bid Laws. /s/ Michael Boquet, Chairman Terrebonne Council on Aging, Inc. Publish: October 1, 8, 15 2024 LLOU0166416

THE STATE OF LOUISIANA 32ND JUDICIAL DISTRICT COURT PARISH OF TERREBONNE REGIONS BANK VS. NO. 199872 MATHEW J. DODGE BE IT KNOWN AND REMEMBERED,, That by Virtue of and in obedience to a WRIT OFSEIZURE AND SALE emanating from the above named Court in the above entitled and numberedsuit and to me directed, this date of 5/21/24, I, TIMOTHY SOIGNET., SHERIFF, duly sworn andqualified in and for the Parish of Terrebonne, State of Louisiana, have seized and will offer for sale atpublic auction WITHOUT appraisal to the last and highest bidder, in the Court House Annex at theGoode Street Entrance located at the Northeast corner of the Court House Annex in the City of Houma,Louisiana, on 10/16/24. Between the hours of 10:00 OClock A. M. and 4:00 P. M., the followingdescribed property, to wit: One certain lot of ground situated in the Parish of Terrebonne, Louisiana, about ten (10) miles below theCity of Houma, designated as LOT FOURTEEN (14) OF BLOCK "A" OF FAITH SUBDIVISION, asshown on the plat entitled "Faith Subdivision for J. G. Duplantis, on the Right Descending Bank ofBayou Little Caillou in Sections 37, 38 and 39, T18S, RI8E, Terrebonne Parish, Louisiana", made by T.Baker Smith & Son, C.E, dated June 10, 1964, on file and of record in the Office of the Clerk of Court ofTerrebonne Parish, Louisiana, said Lot Fourteen (14) of Block "A" measuring eighty (80') feet front onthe Southeasterly side of Rosemary Avenue, by depth between equal and parallel lines of seventy-oneand 24/100 (71.24') feet to the rear; said lot Fourteen (14) being bounded as follows: Northeasterly byLot Thirteen (13), Southwesterly by Lot Fifteen (15), Southeasterly by Lot Thirty-Four (34) all of saidBlock "A" of said subdivision, and Northwesterly by Rosemary Avenue; together with all buildings andimprovements thereon and all rights, ways, privileges and servitudes thereunto belonging or in anywiseappertaining. One certain lot of ground in the Parish of Terrebonne, Louisiana, in that part thereof known as FaithSubdivision, and being more particularly shown and designated as Lot Thirty-four (34) of Block "A" ona plan entitled "Faith Subdivision for J.G. Duplantis, on the right descending Bank of Bayou PetitCaillou in Sections 37, 38 and 39, T 18 S, R 18 E, Terrebonne Parish, Louisiana", made by T. BakerSmith & Son, C.E., and recorded in the Office of the Clerk of Court, Parish of Terrebonne; which saidlot has a frontage of Eighty (80') feet on the Northerly side of Michael Avenue by depth of Seventy-oneand 24/100 (71.24') feet between equal and parallel lines; being bounded Northerly by Lot 14 of saidBlock "A", Southerly by Michael Avenue, Easterly by Lot 33 and Westerly by Lot 35 of said Block "A";together with all buildings and improvements thereon and all rights, ways, privileges and servitudesthereunto belonging or in anywise appertaining. TERMS CASH OR BANK OFFICIAL/CASHIERS CHECK sufficient to pay and satisfy theWRIT OF SEIZURE AND SALE issued in this case, say the sum of $84749.91, alongWith interest and attorneys fees and all other costs including Sheriffs Office cost and charges. Attorney for plaintiff: EMILY A. MUELLER 3510 N. CAUSEWAY BLVD., SUITE 600METAIRIE, LA 70344 Business - (504) 831-7726 TIMOTHY SOIGNET, SHERIFF TERREBONNE PARISH Ad#10527 9/10, 10/15/2024

THE STATE OF LOUISIANA 32ND JUDICIAL DISTRICT COURT PARISH OF TERREBONNE GMFS LLC VS. NO. 198194 JARNESKEE VONKEE ARCENEAUX A/K/A JARNESKEE V. ARCENEAUX A/K/A JARNESKEE ARCENEAUX AND SHARDELL JACKSON ARCENEAUX A/K/A SHARDELL J. ARCENEAUX A/K/A SHARDELL ARCENEAUX BE IT KNOWN AND REMEMBERED,, That by Virtue of and in obedience to a WRIT OFSEIZURE AND SALE emanating from the above named Court in the above entitled and numberedsuit and to me directed, this date of 9/29/23, I, TIMOTHY SOIGNET., SHERIFF, duly sworn andqualified in and for the Parish of Terrebonne, State of Louisiana, have seized and will offer for sale atpublic auction WITH appraisal to the last and highest bidder, in the Court House Annex at the GoodeStreet Entrance located at the Northeast corner of the Court House Annex in the City of Houma,Louisiana, on 10/16/24. Between the hours of 10:00 OClock A. M. and 4:00 P. M., the followingdescribed property, to wit: One certain piece or portion of ground designated as Lot 13, Block 3, of Cavaness Estates, Phase 4, morefully described on a plat entitled, Cavaness Estates Subdivision, Phase 4, J & D Land DevelopmentPartners, L.L.C., Section 6, T17S - R17E, Terrebonne Parish, Louisiana, prepared by Milford &Associates, Inc., dated May 31, 2007, said Lot 13, Block 3, Phase 4, is described as follows; measuring adistance across the front and north of (65.00') on the west (152.37') across the rear, (65.06') and on theeast (149.57'); bounded on the north by T. Leigh Drive, on the West by Lot 14, Block 3, CavanessEstates, Phase 4, on the south by property owned by Mrs. Jannie N. Amos, or assigns, on the east by Lot12, Block 3, Cavaness Estates, Addendum No. 4, together with all buildings and improvements thereon,and all rights, ways, privileges and servitudes thereto belonging or in anywise appertaining. TERMS CASH OR BANK OFFICIAL/CASHIERS CHECK sufficient to pay and satisfy theWRIT OF SEIZURE AND SALE issued in this case, say the sum of $175635.71, alongWith interest and attorneys fees and all other costs including Sheriffs Office cost and charges. Attorney for plaintiff: COREY J. GIROIR 13541 TIGER BEND RD. BATON ROUGE, LA 70817Business - (225) 756-0373 TIMOTHY SOIGNET, SHERIFF TERREBONNE PARISH Ad#10527312 9/10, 10/15/2024

THE STATE OF LOUISIANA 32ND JUDICIAL DISTRICT COURT PARISH OF TERREBONNE NEWREZ LLC D/B/A SHELLPOINT MORTGAGE SERVICING VS. NO. 199904 THE UNOPENED SUCCESSION OF AND UNKNOWN HEIRS OF JANE M. OBLANDER A/K/A JANE M. OBLANDER A/K/A JANE OBLANDER BE IT KNOWN AND REMEMBERED,, That by Virtue of and in obedience to a WRIT OFSEIZURE AND SALE emanating from the above named Court in the above entitled and numberedsuit and to me directed, this date of 5/28/24, I, TIMOTHY SOIGNET., SHERIFF, duly sworn and qualified in and for the Parish of Terrebonne, State of Louisiana, have seized and will offer for sale atpublic auction WITH appraisal to the last and highest bidder, in the Court House Annex at the GoodeStreet Entrance located at the Northeast corner of the Court House Annex in the City of Houma,Louisiana, on 10/16/24. Between the hours of 10:00 OClock A. M. and 4:00 P. M., the followingdescribed property, to wit: A certain lot of ground situated on the left descending bank of the Bayou Terrebonne, located in the Cityof Houma, Parish of Terrebonne, Louisiana, and being more fully described as follows, to-wit: Measuring sixty-two (62') feet front on the northern line of the eastern prolongation of Fane Street to theproperty of Dr. B.R. Walton, now or formerly, and extending back a depth of one hundred twenty (120')feet between parallel lines to the property of Mrs. Onezippe Avel, now or formerly; being bounded asfollows, to-wit: On the south by the northern line of the eastern prolongation of Fane Street; on thenorth by property of Mrs. Onezippe Avel; on the east by property of Dr. B. F. Walton; and on the westby property of Mrs. Beulah Kelly. Being one and the same as property shown on plat of survey entitled "Survey of Tract A-B-C-D-Aproperty in the possession of Larry J. Hutchinson in Section 7, T17S-R17E, Terrebonne Parish,Louisiana" prepared by Keneth L. Rembert, dated July 1, 1987, and recorded under entry number806210, records of Terrebonne Parish, Louisiana, and more fully described as follows, to-wit: Measuringsixty-two and 80/100 (62.80') feet on the north side of Fane Street, by a depth on its east side of onehundred twenty-five and no/100 (125.00') feet, by a depth on its west side of one hundred twenty-five and50/100 (125.50') feet, and having a width on its rear or north side of sixty and 85/100 (60.85') feet, andbeing bounded as follows, to-wit: South or front by Fane Street, east by preoprty of Terre Quip. Inc., orassigns, on the west by Lot 8, Block 8, Margaret Place Subdivision and on the rear by Lot 5, Block 1,Vigurie Subdivision. TERMS CASH OR BANK OFFICIAL/CASHIERS CHECK sufficient to pay and satisfy theWRIT OF SEIZURE AND SALE issued in this case, say the sum of $48542.96, alongWith interest and attorneys fees and all other costs including Sheriffs Office cost and charges. Attorney for plaintiff: DENNIS F. WIGGINS JR. 13541 TIGER BEND RD. BATON ROUGE, LA70817 Business - (225) 756-0373; Fax - (225) 756-5311 TIMOTHY SOIGNET, SHERIFF TERREBONNE PARISH Ad#10525864 9/10, 10/15/2024